Terms & Conditions

Introduction

Welcome to Aliancy Technologies. By accessing or using our website, you agree to these Terms & Conditions. Please read them carefully. If you do not agree, you must not use our website or services.

Use of Website

You may access and use this website for lawful purposes only. You agree not to:

• Violate any applicable laws or regulations.
• Interfere with the website’s functionality or security.
• Attempt unauthorized access to any part of the website, systems, or networks.

Intellectual Property

All content, including text, images, logos, graphics, and software on this website, is owned by Aliancy Technologies or its licensors and protected by copyright and other intellectual property laws. Unauthorized use is prohibited.

Third-Party Links

Our website may contain links to third-party websites. Aliancy Technologies is not responsible for the content, privacy practices, or accuracy of external sites. Accessing them is at your own risk.

Limitation of Liability

Aliancy Technologies and its team are not liable for any damages arising from your use of the website or reliance on its content. Use the website at your own risk.

Termination

We reserve the right to suspend or terminate your access to the website for any violation of these Terms & Conditions, without prior notice.

Modifications

We may update these Terms & Conditions at any time. Changes will be posted on this page with an updated effective date. Continued use of the website constitutes acceptance of the revised terms.

Governing Law

These Terms & Conditions are governed by the laws of India. Any disputes arising from these terms shall be resolved exclusively in the courts of India.

Contact Us

For questions regarding these Terms & Conditions, please contact us at: support@aliancytechnologies.com
Phone: +91-123-456-7890

IT Services Specific Terms

In these terms, “Aliancy Technologies”, “we”, “our”, or “us” refers to Aliancy Technologies, an India-based IT and software development company. The following terms apply specifically to our IT services, projects, and client engagements:

1. Project Agreement & Acceptance

All projects are governed by a mutually signed agreement between Aliancy Technologies and the client. Work officially begins only after both parties approve the project scope, deliverables, and timelines.

2. Project Initiation

Projects commence once the client approves the proposal and provides any necessary resources, access, or information required to start the work. We are not responsible for delays caused by late client input.

3. Initial Payment & Milestones

An initial deposit is required before starting any project. Subsequent milestone payments are defined in the project agreement. Payments should be made according to the agreed schedule. Work may be paused if payments are delayed.

4. Payment on Completion

The final project payment is due upon successful delivery of the agreed deliverables. No deliverables will be handed over until all payments are cleared.

5. Additional Services & Fees

Any additional requests, features, or add-ons beyond the original project scope will incur extra charges. We will provide a quote for such services, and work will proceed only after client approval and payment.

6. Project Deadline & Delays

Project timelines are estimated and documented in the agreement. We make reasonable efforts to meet deadlines but are not liable for delays caused by client inaction, unforeseen circumstances, or third-party dependencies.

7. Client Payment Commitment Failure

Failure by the client to meet payment obligations may result in suspension of services, delay of deliverables, or termination of the project. We reserve the right to recover outstanding amounts legally.

8. Protection of Project Identity & Confidentiality

All project-related information, designs, source code, and proprietary content are confidential. We ensure protection of client data and intellectual property. Clients are also expected to maintain confidentiality and not use any project materials without authorization.

9. Consulting & Advisory Charges

Consulting, advisory, or technical support beyond the agreed scope of work may incur additional fees. Charges will be communicated and invoiced separately, and work will proceed only after client approval.

10. Dispute Resolution

Any disputes arising from the project or service agreement will first be addressed through mutual discussion. If unresolved, disputes will be governed by the laws of India and resolved exclusively in the courts of India.